Terms of Services

Website Design Bozeman

Last Updated: January 2026

Welcome to Website Design Bozeman. These Terms of Services govern your access to and use of our website located at https://websitedesignbozeman.com/ and any services provided by Website Design Bozeman. By accessing our website, requesting a consultation, purchasing services, or engaging with our business in any manner, you agree to be bound by these Terms of Services. If you do not agree with any part of these terms, you must discontinue use of our website and services.

Acceptance of Terms

By using our website or services, you confirm that you have read, understood, and agreed to these Terms of Services. These terms apply to all visitors, clients, businesses, and individuals who interact with Website Design Bozeman.

We reserve the right to modify, update, or replace these Terms of Services at any time without prior notice. Any changes will become effective immediately upon posting on our website. Continued use of the website or services after updates constitutes acceptance of the revised terms.

Description of Services

Website Design Bozeman provides professional website-related services, which may include website design, website development, website redesign, content integration, basic search engine optimization, website maintenance, hosting coordination, and related digital services.

The exact scope of services for each project will be outlined in a written proposal, estimate, or service agreement. Services are provided based on the information supplied by the client and the agreed scope of work.

Client Eligibility

You must be at least 18 years of age and legally capable of entering into a binding agreement to use our services. By engaging Website Design Bozeman, you represent that you have the authority to enter into this agreement on behalf of yourself or any business entity you represent.

Project Proposals and Estimates

All proposals and estimates are based on information available at the time of consultation. Pricing, timelines, and deliverables are subject to change if the scope of work is altered, additional features are requested, or unforeseen technical issues arise.

Estimates are not binding unless explicitly stated in writing. Any modifications to scope or pricing will be communicated and approved by the client before work continues.

Client Responsibilities

Clients agree to provide timely access to required materials, including but not limited to text content, images, logos, branding assets, hosting credentials, and domain information. Delays in providing materials may result in project delays or additional charges.

Clients are responsible for ensuring that all materials provided are accurate, lawful, and do not infringe on third-party rights. Website Design Bozeman is not responsible for verifying the legality or ownership of client-supplied content.

Project Timelines and Delivery

Project timelines are estimates and depend on client responsiveness, project complexity, and technical requirements. Website Design Bozeman is not responsible for delays caused by client inaction, third-party providers, hosting platforms, domain registrars, or circumstances beyond reasonable control.

Delivery dates are not guaranteed unless explicitly stated in writing.

Revisions and Change Requests

Website Design Bozeman may include a limited number of revisions as specified in the service agreement. Additional revisions or change requests outside the agreed scope may result in additional charges.

Change requests must be submitted in writing and approved before implementation.

Payment Terms

Payment terms are outlined in the proposal or service agreement and may include upfront deposits, milestone payments, or full payment upon completion.

Accepted payment methods may include credit card, electronic payment, check, or other approved methods. All payments are due according to the agreed schedule.

Late or missed payments may result in project suspension, delayed delivery, or termination of services. The client is responsible for any costs associated with payment recovery.

Refund Policy

Due to the custom nature of website design and development services, refunds are not guaranteed once work has commenced. Any refunds, if applicable, will be determined at the sole discretion of Website Design Bozeman based on work completed and expenses incurred.

Intellectual Property Rights

Upon full payment, the client is granted ownership or usage rights to the final website design and content as outlined in the service agreement. Website Design Bozeman retains the right to display completed projects in portfolios, case studies, or promotional materials unless otherwise agreed in writing.

Third-party tools, plugins, fonts, or licensed assets remain subject to their respective licenses.

Website Hosting and Third-Party Services

Website Design Bozeman may assist with hosting setup or third-party integrations but does not guarantee performance, uptime, or security of third-party services.

Clients acknowledge that hosting providers, domain registrars, and software platforms operate independently and are subject to their own terms and conditions.

Maintenance and Support

Ongoing maintenance or support services are provided only if explicitly included in a service agreement. Website Design Bozeman is not responsible for website issues arising after project completion unless covered by a maintenance agreement.

Client Content and Compliance

Clients are solely responsible for ensuring that website content complies with applicable laws, regulations, and industry standards. This includes privacy policies, accessibility requirements, disclaimers, and compliance notices.

Website Design Bozeman does not provide legal advice and is not responsible for regulatory compliance unless explicitly agreed.

Limitation of Liability

To the fullest extent permitted by law, Website Design Bozeman shall not be liable for indirect, incidental, consequential, or special damages arising from the use of our website or services.

Total liability for any claim shall not exceed the amount paid by the client for the specific services giving rise to the claim.

Indemnification

Clients agree to indemnify and hold harmless Website Design Bozeman, its owners, contractors, and affiliates from any claims, damages, losses, liabilities, or expenses arising from client-provided content, misuse of services, or violation of these Terms of Services.

Force Majeure

Website Design Bozeman shall not be liable for delays or failure to perform due to events beyond reasonable control, including natural disasters, power outages, internet failures, labor shortages, government actions, or emergencies.

Termination of Services

Website Design Bozeman reserves the right to suspend or terminate services for non-payment, misuse, abusive behavior, or violation of these terms. Termination does not relieve the client of payment obligations for work completed.

Clients may terminate services by providing written notice, subject to payment for work performed up to the termination date.

Website Use and Restrictions

Users agree not to misuse the website, interfere with functionality, attempt unauthorized access, or engage in activities that violate applicable laws.

Website content may not be copied, reproduced, or distributed without written permission.

Privacy and Data Use

Use of our website and services is also governed by our Privacy Policy. By using our services, you consent to the collection and use of information as outlined in that policy.

Governing Law and Jurisdiction

These Terms of Services are governed by and interpreted in accordance with the laws of the State of Montana. Any disputes shall be resolved exclusively in the courts located within Montana.

Severability

If any provision of these Terms of Services is found to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.

Entire Agreement

These Terms of Services constitute the entire agreement between the client and Website Design Bozeman and supersede all prior agreements, proposals, or understandings.

Contact Information

If you have any questions regarding these Terms of Services, please contact:

Website Design Bozeman
2816 S 30th Ave
Bozeman, MT 59718
Phone: (406) 284-8620
Email: [email protected]